Try   HackMD

< On Letterhead of the company >

Standard Software Development Services Agreement

This Agreement ("Agreement") is made and entered into on [Effective Date] by and between:

  1. [Entity Name], a company organized under the laws of [Jurisdiction], with its principal place of business at [Address] ("Client"), and
  2. [Contractor Name], an independent contractor residing at [Address] ("Contractor").

The parties agree as follows:


1. Scope of Work

  1. Description of Services:
    The Contractor agrees to provide software development services as described in Exhibit A ("Services").

  2. Deliverables:

    • List specific deliverables (e.g., functional software, documentation, testing reports).
    • Include milestones, if applicable.
  3. Specifications: (Optional)
    The Services and Deliverables must conform to the specifications provided by the Client.


2. Term and Termination

  1. Term:
    This Agreement will commence on [Start Date] and remain in effect until [End Date] or until all Services are completed, unless terminated earlier.

  2. Termination:
    Either party may terminate this Agreement:

    • Upon [X] days' written notice for convenience.
    • Immediately for cause (e.g., breach of contract, failure to meet milestones).
    • List the conditions of breach of contract for both parties.
  3. Effect of Termination:
    Upon termination, the Contractor will deliver all work completed to date and return any materials belonging to the Client.


3. Payment Terms

  1. Compensation:

    • The Client will pay the Contractor [amount, e.g., $X/hour, milestone-based payments, or flat fee].
  2. Payment Schedule:

    • Payments will be made upon completion of milestones, as detailed in Exhibit B, or on [specific frequency].
  3. On-Chain Payments (if applicable):

    • Payments will be made in USDC to the Contractor's wallet address: [Wallet Address].
  4. Reimbursement: (if applicable)
    The Client will reimburse pre-approved expenses incurred during the performance of Services.


4. Confidentiality

  1. Confidential Information:
    The Contractor agrees to keep all Client information confidential and not disclose it to any third party without prior written consent.

  2. Duration:
    Confidentiality obligations survive termination of this Agreement for [X] years.


5. Intellectual Property

  1. Ownership:

    • All Deliverables and intellectual property created during this Agreement shall be the exclusive property of the Client.
  2. License to Contractor:
    The Contractor retains no rights to reuse or modify the Deliverables without prior approval from the Client.

  3. Open-Source Licensing: (For Open Source Contributions)

    • The Deliverables developed under this Agreement will be governed by open-source principles and licensed under the [specify license, e.g., MIT License, Apache 2.0 License].
    • Detailed terms regarding ownership, licensing, and repository management are outlined in Exhibit C.
  4. Attribution and Contributions: (For Open Source Contributions)

    • The Contractor and Client may be credited as contributors in project documentation or repositories, consistent with open-source standards.
    • Both parties agree to encourage and manage third-party contributions in line with open-source best practices.
  5. No Proprietary Claims: (For Open Source Contributions)

    • Both parties acknowledge that no proprietary claims may be made on the Deliverables once they are released as open-source software.

6. Warranties

  1. Contractor Warranties:

    • Services will meet agreed-upon specifications and deadlines.
    • Deliverables will meet the standards conveyed to the contractor.
  2. Exclusions:

    • The Contractor is not responsible for issues caused by third-party dependencies or Client-provided information.

7. Liability

  1. Limitation of Liability:
    Neither party will be liable for indirect, incidental, or consequential damages arising from this Agreement.

  2. Cap on Liability:
    The Contractor's total liability is limited to the total fees paid under this Agreement.


8. Dispute Resolution

  1. Governing Law:
    This Agreement will be governed by the laws of [Jurisdiction].

  2. Resolution:
    Disputes will first be resolved through good-faith negotiation, and if unresolved, through binding arbitration in [Location].


9. Force Majeure

Neither party will be liable for delays or failures caused by events beyond their control (e.g., natural disasters, acts of war).


10. Miscellaneous

  1. Entire Agreement:
    This Agreement constitutes the entire understanding between the parties.

  2. Amendments:
    Any changes must be agreed to in writing by both parties.

  3. Notices:
    All notices must be sent to the addresses listed above via [email/registered mail].


11. Signatures

This Agreement is executed as of the Effective Date:

Client:
Name: ____________________________
Title: ____________________________
Signature: ________________________
Date: _____________________________

Contractor:
Name: ____________________________
Signature: ________________________
Date: _____________________________


Exhibit A: Scope of Work

  • Detailed description of services, tasks, and responsibilities.

Exhibit B: Payment Terms

  • Milestone breakdown, deadlines, and associated payment amounts.

Exhibit C: Open-Source Intellectual Property Terms (If Applicable)

  1. Open-Source Licensing:

    • All Deliverables will be released under the [specify license, e.g., MIT License, Apache 2.0 License, GNU GPL].
    • Both parties agree to abide by the terms of the selected license, ensuring the project is freely available for use, modification, and distribution.
  2. Ownership:

    • The Deliverables will be owned collectively by the community under the terms of the open-source license.
    • The Contractor waives proprietary ownership claims once the Deliverables are released.
  3. Pre-Existing Materials:

    • Any pre-existing intellectual property (e.g., libraries, tools) owned by the Contractor and incorporated into the Deliverables must be compatible with the open-source license.
    • The Contractor grants a perpetual, royalty-free license for such materials to the Client and future users within the scope of the project.
  4. Attribution:

    • The Contractor and Client may be credited as contributors in the project documentation or repository.
  5. Third-Party Contributions:

    • Third-party contributions must comply with the open-source license and repository governance.
    • The Contractor will ensure third-party code meets contribution guidelines and licensing requirements.
  6. Repository Management:

    • The Deliverables will be maintained in a publicly accessible repository (e.g., GitHub, GitLab).
    • The Contractor will adhere to best practices for open-source development, including proper documentation, testing, and adherence to coding standards.
  7. Post-Project Use:

    • Once released under the open-source license, the Deliverables may be freely used, modified, or redistributed by any individual or entity in accordance with the license terms.
  8. No Proprietary Claims:

    • As an open-source project, no proprietary claims can be made on the Deliverables by either party.